Telephone Answered 24 Hours A Day Off-Site/Evening & Weekend Appointments Available Please Call Attorney Bill Last
Local:
650-425-7679
Toll Free:
866-904-4725

Have You Given Proper Notice of The Delay? California Appellate Court Permits Assessment of Liquidated Damages Due to Contractor's Failure To Give Notice of Delay.

In a recent case entitled Greg Opinski Construction v. City of Oakdale, 199 Cal.App.4th 1107 (2011) a California Appellate Court held that when a construction contract requires notice be given as a condition for getting an extension of time and notice is not given, the contractor cannot later claim that the delay was caused by the owner. This is noteworthy since it refutes prior precedent that allowed a contractor to assert that the liquidated damages should not be assessed since the public entity delayed the project during a period of owner caused delay.

This decision could have a significant impact on disputes concerning project delays and liquidated damages. While most sophisticated construction contracts include claim provisions relative to schedule extensions for non-contractor cause delays, these provisions are often time ignored by the parties. Many contractors operate under the assumption that regardless of the "fine print" in their contracts requiring notice of delay events, that ultimately a change order or favorable court judgment can eventually be secured so long as the contractor can prove that the owner (or non-contractor caused factors) caused the delay. The Opinski decision makes it clear that simply having the facts on your side is not enough, and that the technical requirements of the "fine print" claim provisions must be complied with.

See a more thorough article on this issue at our website, here.

No Comments

Leave a comment
Comment Information

Our Awards and Professional Legal Associations

  • Rated by Super Lawyers - William C. Last, Jr. - Visit superlawyers.com
  • Avvo Rating - 9.3 Superb - Top Attorney Construction
  • AV Peer Review Rated
  • The State Bar of California
  • San Matco County Bar Association - SMCBA
  • LACBA - Los Angeles County Bar Association
  • American Bar Association Forum on the Construction Industry
  • Bay Area Chapter - SMACNA
  • The Associated General Contractors of America
  • American Subcontractors Association
  • Peninsula Builders Exchange
Email Us For A Response

Contact our attorneys now

Bold labels are required.

Contact Information
disclaimer.

The use of the Internet or this form for communication with the firm or any individual member of the firm does not establish an attorney-client relationship. Confidential or time-sensitive information should not be sent through this form.

close

Privacy Policy

Last & Faoro
520 South El Camino Real, Suite 430
San Mateo, CA 94402

Toll Free: 866-904-4725
Phone: 650-425-7679
Fax: 650-696-8365
Map & Directions

Map